KDA Signature Designs and Fitout LLC Dubai, United Arab Emirates Email: info@kdasignature.ae 1. Introduction These Terms & Conditions govern the use of this website and the professional services provided by KDA Signature Designs and Fitout LLC, a Limited Liability Company registered in Dubai, United Arab Emirates. By accessing this website or engaging our services, you agree to comply with these Terms. 2. Company Services KDA Signature Designs and Fitout LLC provides custom-based services including but not limited to: Interior Design Execution & Fit-Out Works Renovation Services Custom Furniture Office Interiors Commercial & Residential Projects All services are offered strictly on a custom quotation basis. No fixed packages are offered. A formal written contract will be issued and must be signed before project commencement. 3. Quotations & Payments All quotations are valid for the period stated in the proposal. For commercial projects, an advance payment is mandatory before work begins. Payment schedules will be clearly defined in the signed agreement. Failure to adhere to payment terms may result in suspension of services. 4. Cancellations & Refund Policy Project cancellations are permitted only under written request. A cancellation fee will apply depending on project stage and incurred costs. All payments made are non-refundable once the project is confirmed and work has commenced. 5. Warranty KDA Signature Designs and Fitout LLC provides a limited 10-year warranty, subject to: Scope defined in the signed contract Proper usage and maintenance Exclusion of misuse, third-party alterations, or force majeure events Warranty terms will be detailed in the project agreement. 6. Delays & Liability The Company shall not be held liable for delays caused by: Government approvals or regulatory authorities Material shortages or supplier delays Client-requested changes Third-party contractors engaged by the client Force majeure events (natural disasters, unforeseen events) Project timelines may be adjusted accordingly. 7. Third-Party Contractors Clients may engage third-party contractors. However, KDA Signature Designs and Fitout LLC is not liable for: Work quality of third parties Delays caused by them Damage arising from their involvement 8. Intellectual Property All content on this website, including: Designs Drawings Concepts Images Logos Brand identity Text content is the exclusive intellectual property of KDA Signature Designs and Fitout LLC. Unauthorized copying, reproduction, modification, or distribution is strictly prohibited. Project images are copyrighted. 9. Marketing & Portfolio Usage The Company reserves the right to photograph and use completed projects for: Portfolio display Website Social media Marketing materials Clients may refuse photography in writing before project completion. 10. Website Usage Users may not: Copy or reproduce website content Use company logo or brand name without permission Attempt to disrupt or hack website systems Unauthorized use may result in legal action. 11. Dispute Resolution These Terms are governed by the laws of the United Arab Emirates. In the event of a dispute: Jurisdiction shall fall under the Courts of Dubai. The Company may opt for arbitration where applicable. 12. Amendments KDA Signature Designs and Fitout LLC reserves the right to modify these Terms at any time. Updated versions will be published on this website.